NOTICE TO BIDDERS
DIRT WORK AT ACKERMAN SPORTSPLEX
The Town of Ackerman, MS will receive bids until 4:00 p.m. Monday, May 1, 2023 to cut and shift 31,000 yards of existing dirt and to import 15,000 yards of select fill dirt to bring the “NEW” Sportsplex to grade.
Bids sheets can be obtained at Town Hall between the hours of 7:30 a.m. to 5:00 p.m., Monday through Thursday and 7:30 a.m. to 11:30 a.m. on Friday. CONTRACTOR LICENSE NUMBER IS REQUIRED.
The Mayor and Board of Aldermen reserves the right to reject any and all bids received, or to accept any bids which is deemed most favorable to the Town of Ackerman. Bids will be received at Town Hall, 45 E. Main Street, Ackerman, MS 39735. Phone 662-285-6251.
/s/ Debbie Cagle Boley
Town Clerk
Publication Dates: 4/14, 4/21, & 4/28/2023
***
SUMMONS BY PUBLICATION
IN THE CHANCERY COURT OF CHOCTAW COUNTY, MISSISSIPPI
CIVIL ACTION FILE NO. 2022-0089
IN THE MATTER OF THE ESTATE
NANCY D. HENDERSON, DECEASED
JIMMY HENDERSON, PETITIONER
SUMMONS
THE STATE OF MISSISSIPPI
TO: ALL THE KNOWN AND UNKNOWN HEIRS AT LAW OF NANCY D. HENDERSON, DECEASED
You have been made Defendants in the suit filed in this Court by Jimmy Henderson, Administrator, seeking to determine all of the heirs at law of Nancy D. Henderson, deceased.
Defendants other than you in this action, are any and all other persons claiming to be an heir at law of Nancy D. Henderson, deceased.
You are summoned to appear and defend against said Complaint at 9:00 A.M., on the 18th day of May, 2023, in the Courtroom of the Attala County Chancery Courthouse in Kosciusko, Mississippi, and in case of your failure to appear and defend a judgment will be entered against you for the money or other things demanded in the Petition for Determination of Heirs.
You are not required to file an answer or other pleading but you may do so if you desire.
Issued under my hand and the seal of said court, this the 3rd day of April, 2023.
/s/ Steve Montgomery,
Clerk of the Chancery Court
Choctaw County
PO Box 250
Ackerman, Mississippi 39735
By: /s/ Laila Henson, D.C.
NETTLES & RHEA
ATTORNEYS AT LAW
Post Office Box 148
117 North Van Buren Street
Carthage, Mississippi 39051
Tele: (601) 267-8404
Mississippi Bar No. 3815
Publish: 4/14, 4/21, 4/28/2023
***
NOTICE
STATE OF MISSISSIPPI
COUNTY OF CHOCTAW
TO:
1. Ronald Morrow, 5912 Shortcut Rd, Moss Point, MS 39563
NOTICE TO PARTIES
You are hereby notified by the Town of Ackerman that a hearing will be held at 5:00 p. m. May 2, 2023, before the Board of Alderman of the Town of Ackerman, Mississippi at Town Hall in the Town of Ackerman, Mississippi. At such hearing, the Town of Ackerman will consider whether your property is in a state of uncleanliness so as to be a menace to the public health and safety of the community pursuant to Section 21-19-11 of the Mississippi code of 1972.
If your property is deemed to be such a menace. and the Town is forced to clean the property, you may be assessed the sum of $1500.00, or 50 % of the actual cost of such cleaning, said property is described as follows:
house and property located at 5 E Cherry St, Ackerman. MS 39735
Issued under my hand and the seal of said town, this the 4th day of April, 2023.
(Seal)
/s/ Debbie Boley
Debbie Boley, City Clerk
Town of Ackerman, Mississippi
Publish: 4/21, 4/28/2023
***
ADVERTISEMENT FOR BIDS
TOWN OF WEIR / MDOT
UTILITY RELOCATION
Part 1: Water Main Relocation
Part 2: Sanitary Sewer Relocation
Part 3: Natural Gas Relocation
(CES Project #22-1422)
Sealed bids will be received by the Town of Weir, Mississippi until 2:00PM on Friday, June 09, 2023 at the Town Hall in the Town of Weir, 360 Front Street, Weir, Mississippi 39772. All bids will be thereafter publicly opened for the construction of utility relocations, said project being named above.
The Work shall generally consist of the following:
Part 1: Water Main Relocation- 194 linear feet of 4” PVC water main, 76 linear feet of steel casing (bore and jack), necessary valves, fittings, and connections.
Part 2: Sanitary Sewer Relocation - Construct Sanitary Sewer Manhole, connection to existing gravity sewer collector, construct 103 linear feet of later service piping, connections to existing residential service lines.
Part 3: Natural Gas Main Relocation – Construct line stopper fitting, cut and cap existing steel main, construct necessary valves, fittings, and connections.
Contracts to construct each part (Part 1, Part 2, Part 3) will be awarded.
The Owner (Town of Weir, MS) reserves the right to increase, decrease, or delete any pay item to as required to construct the project or to stay within the project budget.
Contract Time for each part (Part 1, Part 2, Part 3) of the project is thirty-five (35) Working Days with a liquidated damages provision of one hundred dollars ($100.00) per Working Day thereafter.
The Awards, if made, will be made to the lowest and best qualified bidder on the basis of the published quantities.
Plans and specifications are on file in the Town Clerk’s Office and the Project Engineer's office. This project shall be constructed in accordance with the contract documents and specifications contained within the latest edition of the Mississippi Standard Specifications for State Aid Road and Bridge Construction.
PLANS AND PROPOSALS may be secured from Thomas M. (Marty) Crowder, P.E., Project Engineer, c/o Crowder Engineering & Surveying, Inc., P. O. Box 1209, Ackerman, MS 39735 (662-285-2062). The Cost is fifty dollars ($50.00) for printed plans and fifty dollars ($50.00) for the printed proposal, non-refundable. Plans and Proposals may also be downloaded electronically for a non-refundable fee of $25.00 by providing QuestCDN Project Number 8482747 on the Project Search Page on the Quest website www.questcdn.com.
A certified check or Bid Bond equal to five percent (5%) of the total Bid, made payable to the Town of Weir, must accompany each Bid proposal.
All Bidders responding to this Advertisement for Bids must comply with all applicable requirements of Chapters 3 and 5 of Title 31 of the Mississippi Code of 1972, as amended, including, but not limited to, the requirements relative to holding a Certificate of Responsibility and payment of a special privilege tax; both items administered by the Mississippi State Board of Public Contractors.
All Bids received shall display the Bidder’s Certificate of Responsibility Number on the outside of the sealed envelope containing the Bidder’s proposal.
The Successful Bidder must provide both a Performance Bond and a Payment Bond (each in the amount of one hundred percent [100%] of the Contract) upon execution of the Contract.
No Bidder may withdraw his Bid within Sixty (60) days after the actual date of the opening thereof. Within the limitations of the state law, the Town of Weir reserves the right to reject any or all bids received, to waive any informalities or irregularities in the bids received, or to accept any bid that is deemed most favorable to the Town of Weir.
By: /s/ Stewart Glen Beard
Stewart Glen Beard, Mayor
Town of Weir, Mississippi
Publish: April 28, 2023, May 05, 2023
***
ADVERTISEMENT FOR BID
CONSTRUCTION OF BASE & PAVE ON VARIOUS ROUTES IN CHOCTAW COUNTY
PART A: CONSTRUCTION OF SOIL-CEMENT BASE STABILIZATION
PART B: CONSTRUCTION OF BITUMINOUS SURFACE TREATMENT
CES Project #23-1416
CHOCTAW COUNTY, MISSISSIPPI
The CHOCTAW COUNTY BOARD OF SUPERVISORS will receive competitive, sealed bids in the Office of Chancery Clerk of Choctaw County, Mississippi at the Choctaw County Courthouse, 22 E Quinn Street, in Ackerman, Mississippi 39735 until 10:00 a.m. on Monday, June 5th, 2023 for the Construction of Base & Pave on Various Routes in Choctaw County, CES Project #23-1416: Part A- Construction of Soil-Cement Base Stabilization; Part B- Construction of Bituminous Surface Treatment. (Two Contracts).
Detailed plans and specifications for the above described work are on file in the Chancery Clerk’s Office at the Choctaw County Courthouse, 22 E Quinn Street in Ackerman, Mississippi. Plans and Proposals may be secured by contacting Marty Crowder, P.E., County Engineer, 1150 West Main Street, Ackerman, Mississippi 39735, 662-285-2062. The cost is one-hundred dollars ($100) for printed plans and proposal package, non-refundable.
Certified check or bid bond for five percent (5%) of the total bid, made payable to Choctaw County must accompany each proposal. The successful Bidders will be required to furnish separate performance and payment bonds each in the amount equal to 100% of the contract price at the time of execution.
It shall be incumbent upon each bidder to understand the specifications as listed herein and to obtain clarification when necessary.
Published by Order of the Board of Supervisors of Choctaw County, Mississippi dated April 17, 2023.
/s/Joey Stephenson
JOEY STEPHENSON, PRESIDENT
BOARD OF SUPERVISORS
CHOCTAW COUNTY, MISSISSIPPI
Publication Dates: April 28, 2023 and May 05, 2023
