NOTICE TO BIDDERS
Notice is hereby given by the Board of Supervisors, Choctaw County, Ackerman, Mississippi, that it will receive sealed bids until the hour of 10:00 A.M., January 3, 2022, for the sale to the county, certain supplies, commodities, goods, and services over a period of 12 months beginning January 3, 2023. Bids must be submitted as term bids according to estimated quantities as follows:
ROAD GRAVEL: 18,000 yards per year, No. 1 or equivalent, free of mud and foreign matter. FOB vendor plant and/or FOB jobsite within Choctaw County Mississippi.
CULVERTS: All sizes of virgin plastic and metal pipe, FOB district barns or work sites, price per foot including delivery cost. Maximum lengths must be quoted in bid.
The Board intends to accept the lowest and best bids but reserves the right to reject any and or all bids. Site and conditions of site for pickup will be stated in quote by bidder. Ease of pickup and stress on county equipment involved in pickup will be considered in total cost of product.
Steve Montgomery
Chancery Clerk
**************
LEGAL NOTICE
PUBLICATION FOR BIDS TO KEEP COUNTY FUNDS
Pursuant to the provisions of Section 27-105-305 (Chapter 105 Article 3) of the Mississippi code of 1972, notice is hereby given that the Board of Supervisors in and for Choctaw County, Mississippi, will receive sealed bids at the office of the Chancery Court Clerk in and for Choctaw County, Mississippi, at the Choctaw County Courthouse in the Town of Ackerman, Mississippi, until the hour of 9:00 a..m., on Monday, January 3, 2022, for a depository for keeping all county funds, or any part thereof, during the calendar year 2022, or for the calendar years 2019/2020, including all funds collected by law. On the day the commission will be available to the bank or banks proposing the best terms and having in view the safety of said funds and the bank or banks selected as depository or depositories for the year, 2022, or for the years 2022/2023, will be required to furnish bond or other securities as required by law. The bid or proposal shall designate the kind of security as authorized by law, which said banks propose to give as security for funds deposited. The bid or proposal should also include in their bid that no service charges, no analysis fees shall be charged on all county accounts, or any other fees which may be considered. The bid shall also include if any accounts are excluded from earning interest quoted.
The Board reserves the right to reject any and or all bids.
Choctaw County Board of Supervisors
Joey Stephenson, President
Steve Montgomery, Clerk of the Board
*************
IN THE CHANCERY COURT OF CHOCTAW COUNTY MISSISSIPPI
IN THE MATTER OF THE ESTATE OF
FREDRIC GWENDOLYN LITTLE, DECEASED
CAUSE NO. 2021-92
SUMMONS
STATE OF MISSISSIPPI
COUNTY OF CHOCTAW
TO:
Anyone unknown heirs at law of Fredrick Gwendolyn Little, all of whom are adult non-resident of the State of Mississippi, or not to be found therein after diligent search and inquiry, and whose last street and post address are unknown to petitioners despite diligent search and inquiry in an effort to ascertain the same.
NOTICE TO DEFENDANT
You have been made a respondent in the Plaintiff’s petition to determine heirship. Respondents other than you are: none.
You are summoned to appear and defend against said complaint or petition at 9:00 o'clock a.m. on the 13th day of January 2022 in the courtroom of the Attala County Chancery Court Building in Kosciusko Mississippi and in case of your failure to appear and defend a judgment will be entered against you for the money or other things demanded in the complaint or petition.
You are not required to file an answer or other pleading but you may do so if you desire.
Issued under my hand and the seal of said Court, this the 3rd day of December, 2021.
(Seal)
/s/ STEVE MONTGOMERY
Choctaw County Chancery Clerk
Publish: 12/8, 12/15, 12/22/2021
*************************
IN THE CHANCERY COURT OF CHOCTAW COUNTY, MISSISSIPPI
IN THE MATTER OF THE
CONSERVATORSHIP
CAUSE NO. 21-38
DON MCCOY, AN adult incompetent
BY PETITIONER(S) JON MCCOY
THE RELIEF SOUGHT HEREIN MAY AFFECT YOUR LEGAL RIGHTS. YOU HAVE ARIGHT TO NOTICE OF ANY HEARING ON THIS PETITION, TO ATTEND ANY SUCH HEARING, AND TO BE REPRESENTED BY AN ATTORNEY.
SUMMONS
STATE OF MISSISSIPPI
COUNTY OF CHOCTAW
TO:
Chandra Armstead McCoy, an adult non-resident of the State of Mississippi, or not to be found therein after diligent search and inquiry, and whose last street and post address is 102 W 7th St, New York, NY 10023
Craig Lewis, an adult non-resident of the State of Mississippi, or not to be found therein after diligent search and inquiry, and whose last street and post address is 220 Northpoint Dr, Houston, TX 77060
NOTICE TO DEFENDANT
You have been made a respondent in the Plaintiff’s amended Petition to appoint conservator and guardian. Respondents other than you are: Katina McGhee-Williams, Ericka Moore, and Don McCoy.
You are summoned to appear and defend against said complaint or petition at 9:00 o'clock a.m. on the 11th day of January 2022 in the courtroom of the Choctaw County Courthouse in Ackerman, Mississippi and in case of your failure to appear and defend a judgment will be entered against you for the money or other things demanded in the complaint or petition.
You are not required to file an answer or other pleading but you may do so if you desire.
Issued under my hand and the seal of said Court, this the 1st day of December, 2021.
(Seal)
/s/ STEVE MONTGOMERY
Choctaw County Chancery Clerk
Publish: 12/8, 12/15, 12/22/2021
********************
IN THE CHANCERY COURT OF CHOCTAW COUNTY MISSISSIPPI
IN THE MATTER OF THE ESTATE OF
RUSSELL BURTON, DECEASED
CAUSE NO. 2021-124
NOTICE TO CREDITORS
STATE OF MISSISSIPPI
COUNTY OF CHOCTAW
Letters of Administration having been granted the undersigned Administrator of the Estate of RUSSELL BURTON, deceased, by the Chancery Court of Choctaw County, Mississippi, on the 1st day of December, 2021, in CAUSE NO. 2021-124, on the docket of said Court, notice is hereby given to all persons having claims against said estate to present the same to the Clerk of this Court for probate and registration according to law within ninety (90) days from the date of the first publication of this notice or said claims will be forever barred.
This the 1st day of December, 2021.
/s/ JULIE SALLEY
Administrator of the Estate of
RUSSELL BURTON
Kevin Null
Attorney at Law
P. O. Box 756
Ackerman, MS 39735
(662) 285-3880
Attorney for Administratrix
Publish: 12/8, 12/15, 12/22/2021
*******************
NOTICE TO BIDDERS
Notice is hereby given by the Board of Supervisors, Choctaw County, Ackerman, Mississippi, that it will receive sealed bids until the hour of 10:00 A.M., January 3, 2022, for the sale to the county, certain supplies, commodities, goods, and services over a period of 12 months beginning January 3, 2023. Bids must be submitted as term bids according to estimated quantities as follows:
ROAD GRAVEL: 18,000 yards per year, No. 1 or equivalent, free of mud and foreign matter. FOB vendor plant and/or FOB jobsite within Choctaw County Mississippi.
CULVERTS: All sizes of virgin plastic and metal pipe, FOB district barns or work sites, price per foot including delivery cost. Maximum lengths must be quoted in bid.
The Board intends to accept the lowest and best bids but reserves the right to reject any and or all bids. Site and conditions of site for pickup will be stated in quote by bidder. Ease of pickup and stress on county equipment involved in pickup will be considered in total cost of product.
Steve Montgomery
Chancery Clerk
Publish: 12/8, 12/15/2021
****************
SECTION 000100 - ADVERTISEMENT FOR BIDS
Notice is hereby given that sealed bids will be received for the project named below by the Choctaw County School District at 2:00 p.m. on Tuesday, January 11, 2022. Electronic bids may be submitted through the website www.baileyarchplanroom.com. Electronic bids are not required by the CCSD, but offered as another means to submit a bid. Single stipulated sum bids will be received for all work required by the contract documents in accordance with the Instructions to Bidders.
Location for Receipt of Bids:
Choctaw County School District
19 East Main Street
Ackerman, MS 39735
Plans and Specifications Entitled:
Choctaw County School District Remote Learning Center Re-Bid
Ackerman, Mississippi
Project Number: 20096
- Bid documents may be examined at the office of the Architect.
- Bid documents are being made available via original paper copy or digital CD. Plan holders are required to register and order bid documents at www.baileyarchplanroom.com. Bid documents are non-refundable and must be purchased through the website. All plan holders are required to have a valid email address for registration. Questions regarding website registration and online orders please contact Plan House Printing, 607 W. Main Street, Tupelo, MS 38804, (662) 407-0193.
- Bid Documents will only be made available to plan holders as entire documents. Partial sets will not be issued.
A Pre-Bid Conference will be conducted at Choctaw County School District, 19 East Main Street, Ackerman, MS 39735 beginning at 10:00 AM on Tuesday, 04 January 2022. All prospective Bidders are encouraged to attend.
Proposals shall be submitted in duplicate only upon the blank proposal forms provided with the specifications and must be accompanied by Proposal Security in the form of Certified Check or acceptable Bid Bond in the amount equal to at least five percent (5%) of the Base Bid: such security to be forfeited as liquidated damages, not penalty, by any bidder who fails to carry out the terms of the proposal, execute a contract and post Performance and Payment Bonds in the form and amount within the time specified. The Bid Bond, if used, shall be payable to the Owner.
Bid proposals must be received on or before the scheduled time for opening of bids and no bid may be withdrawn after the declared closing time for the receipt of bids for a period of forty-five (45) days.
All bids submitted in excess of $50,000 by a prime or Subcontractor to do any erection, building, construction, repair, maintenance, or related work must comply with the Mississippi Contractors Act of 1985, by securing a Certificate of Responsibility from the State Board of Contractors.
The Owner reserves the right to waive any irregularities, the right to reject any or all bids and the option to postpone action and final decision for a period of up to forty-five (45) days.
OWNER:
Choctaw County School District
19 East Main Street
Ackerman, MS 39735
ARCHITECT:
Bailey Architecture Education, P.A.
201 Park Court, Suite B
Ridgeland, MS 39157
Phone: (601) 760-9432
Fax: (866) 614-8296
DATES OF ADVERTISEMENT: Wednesday, December 08, 2021
Wednesday, December 15, 2021
END OF SECTION 000000
************************
LEGAL NOTICE
PUBLICATION FOR BIDS TO KEEP COUNTY FUNDS
Pursuant to the provisions of Section 27-105-305 (Chapter 105 Article 3) of the Mississippi code of 1972, notice is hereby given that the Board of Supervisors in and for Choctaw County, Mississippi, will receive sealed bids at the office of the Chancery Court Clerk in and for Choctaw County, Mississippi, at the Choctaw County Courthouse in the Town of Ackerman, Mississippi, until the hour of 9:00 a..m., on Monday, January 3, 2022, for a depository for keeping all county funds, or any part thereof, during the calendar year 2022, or for the calendar years 2021/2022, including all funds collected by law. On the day the commission will be available to the bank or banks proposing the best terms and having in view the safety of said funds and the bank or banks selected as depository or depositories for the year, 2022, or for the years 2022/2023, will be required to furnish bond or other securities as required by law. The bid or proposal shall designate the kind of security as authorized by law, which said banks propose to give as security for funds deposited. The bid or proposal should also include in their bid that no service charges, no analysis fees shall be charged on all county accounts, or any other fees which may be considered. The bid shall also include if any accounts are excluded from earning interest quoted.
The Board reserves the right to reject any and or all bids.
Choctaw County Board of Supervisors
Joey Stephenson, President
Steve Montgomery, Clerk of the Board
Publish: 12/8, 12/15/2021
*****************
SECTION 000100 - ADVERTISEMENT FOR BIDS
Notice is hereby given that sealed bids will be received for the project named below by the Choctaw County School District at 2:00 p.m. on Tuesday, January 11, 2022. Electronic bids may be submitted through the website www.baileyarchplanroom.com. Electronic bids are not required by the CCSD, but offered as another means to submit a bid. Single stipulated sum bids will be received for all work required by the contract documents in accordance with the Instructions to Bidders.
Location for Receipt of Bids:
Choctaw County School District
19 East Main Street
Ackerman, MS 39735
Plans and Specifications Entitled:
Choctaw County School District Remote Learning Center Re-Bid
Ackerman, Mississippi
Project Number: 20096
- Bid documents may be examined at the office of the Architect.
- Bid documents are being made available via original paper copy or digital CD. Plan holders are required to register and order bid documents at www.baileyarchplanroom.com. Bid documents are non-refundable and must be purchased through the website. All plan holders are required to have a valid email address for registration. Questions regarding website registration and online orders please contact Plan House Printing, 607 W. Main Street, Tupelo, MS 38804, (662) 407-0193.
- Bid Documents will only be made available to plan holders as entire documents. Partial sets will not be issued.
A Pre-Bid Conference will be conducted at Choctaw County School District, 19 East Main Street, Ackerman, MS 39735 beginning at 10:00 AM on Tuesday, 04 January 2022. All prospective Bidders are encouraged to attend.
Proposals shall be submitted in duplicate only upon the blank proposal forms provided with the specifications and must be accompanied by Proposal Security in the form of Certified Check or acceptable Bid Bond in the amount equal to at least five percent (5%) of the Base Bid: such security to be forfeited as liquidated damages, not penalty, by any bidder who fails to carry out the terms of the proposal, execute a contract and post Performance and Payment Bonds in the form and amount within the time specified. The Bid Bond, if used, shall be payable to the Owner.
Bid proposals must be received on or before the scheduled time for opening of bids and no bid may be withdrawn after the declared closing time for the receipt of bids for a period of forty-five (45) days.
All bids submitted in excess of $50,000 by a prime or Subcontractor to do any erection, building, construction, repair, maintenance, or related work must comply with the Mississippi Contractors Act of 1985, by securing a Certificate of Responsibility from the State Board of Contractors.
The Owner reserves the right to waive any irregularities, the right to reject any or all bids and the option to postpone action and final decision for a period of up to forty-five (45) days.
OWNER:
Choctaw County School District
19 East Main Street
Ackerman, MS 39735
ARCHITECT:
Bailey Architecture Education, P.A.
201 Park Court, Suite B
Ridgeland, MS 39157
Phone: (601) 760-9432
Fax: (866) 614-8296
DATES OF ADVERTISEMENT:
Wednesday, December 08, 2021
Wednesday, December 15, 2021
